HIDRA

HIDRA

DISPOSIZIONI GENERALI

GENERAL CONDITIONS

Condizioni generali di vendita

General sales conditions

Le presenti condizioni di vendita e di consegna si intendono integralmente accettate dal Committente con il conferimento dell’ordine o con il

ritiro dei materiali. Vengono respinte le eventuali condizioni generali di contratto del Compratore.

ACCETTAZIONE ORDINI

Gli ordini sono da intendersi subordinati all’accettazione di Hidra Ceramica Srl.

PREZZI

I prezzi possono essere variati senza nessun preavviso e si intendono pattuiti secondo i listini in vigore al momento della consegna. I prezzi

contenuti nel presente listino sono da intendersi franco fabbrica e IVA esclusa.

PAGAMENTO

I termini di pagamento si intendono tassativi e decorrono dalla data di fatturazione. I pagamenti devono essere effettuati direttamente ad

Hidra Ceramica Srl presso la sua sede. Qualsiasi ritardo imputabile al Committente o qualsiasi contestazione sorgesse fra le parti, anche

relativamente alle garanzie concesse, non produrrà alcun prolungamento o modifica nei termini dei pagamenti convenuti ed ogni azione ed

eccezione del Committente non sarà ritenuta procedibile, se lo stesso non prover

à di essere in regola coi pagamenti. Nel caso di mora in

qualsiasi pagamento potranno essere sospese ed annullate le forniture in corso. Decorso il termine di pagamento stabilito in fattura senza

che ne sia avvenuto il regolamento, Hidra Ceramica Srl avrà la facoltà di emettere tratta a vista per l’ammontare dell’intero credito aumentato

delle spese. L’eventuale ritardo nel pagamento comporterà l’addebito di interessi al tasso corrente di mercato, aumentato del 2%. Nel caso di

inosservanza di uno dei termini di scadenza anche tutte le altre fatture del venditore saranno immediatamente esigibili. L’esigibilità di tutte

le fatture si verifica anche nell’ipotesi in cui il venditore venga a conoscenza di altre circostanze che lascino temere una cattiva situazione

finanziaria del compratore (per esempio: emissione di assegni scoperti, cambiali protestate, procedimenti di sequestro, ecc.)

TERMINI DI CONSEGNA, RITARDI O IMPEDIMENTI DI FORNITURA

Allorché viene indicato un termine di consegna, questo ha valore semplicemente informativo e non impegnativo, essendo subordinato a

qualunque imprevisto. La consegna della merce si intende eseguita con la messa a disposizione della merce presso il nostro stabilimento di

Civita Castellana (Italia). Interruzioni di lavoro conseguenti a cause di forza maggiore dispensano Hidra Ceramica Srl dall’osservare il termine di

consegna indicato, senza peraltro dare diritto al Committente di esigere risarcimenti dovuti a danni di qualsiasi natura. La merce dovrà essere

sempre ritirata dal Committente e non dovrà essere in ogni caso lasciata giacente. Le eventuali spese di giacenza, magazzinaggio, ecc. saranno

comunque a carico del Committente.

TRASPORTO

Salve condizioni particolari, la merce

è venduta franco nostro stabilimento ed in ogni caso viaggia a rischio e pericolo del Committente anche

se resa franco destino. Sono consentite forniture parziali e anticipate. Il trasporto è a carico del Committente. Le spedizioni avvengono per

conto ed incarico del Committente, il quale, in caso di avarie, rotture o ammanchi, deve notificarlo alla nostra azienda, tramite il vettore, al

momento della consegna. La merce consegnata rimane di riservato dominio della venditrice fino all’avvenuto pagamento. I termini di consegna

si intendono sempre indicativi ed in relazione alle possibilità del momento. Non si assume nessuna responsabilità per ritardi o mancate

consegne per fatti o atti indipendenti dalla nostra volontà ed eventuali richieste di risarcimento danni per ritardi di consegna non saranno

accettati.

IMBALLAGGIO

L’imballaggio viene effettuato in pallets e retraibile. Il costo dell’imballaggio è a carico del Committente, salvo patto contrario risultante dalla

conferma d’ordine. A parziale recupero delle spese di imballo viene addebitato il 3%.

RESPONSABILITA’

Qualora il materiale risultasse difettoso per vizi di fabbricazione riconosciuti a seguito di accertamenti tecnici, Hidra si riserva di sostituirlo

o accreditare il valore nei tempi previsti dalla Normativa vigente . In alcun caso la responsabilità può estendersi ai danni diretti e indiretti che

dovessero derivare anche dalla messa in opera del materiale difettoso. E’ fatto onere al compratore di controllare ogni articolo non appena

preso in consegna, e così in particolare di aprire le confezioni, gli imballaggi e le scatole di contenimento; il termine decadenziale di legge per i

vizi evidenti decorre dal momento della consegna stessa.

RECLAMI

Non si accettano reclami di nessun genere trascorsi otto giorni dal ricevimento della merce. Eventuali reclami dovranno essere fatti a mezzo

lettera raccomandata entro tale termine. In ogni caso nessuna contestazione verr

à accettata per materiali già posti in opera.

CARATTERISTICHE TECNICHE E COLORI

Hidra Ceramica Srl si riserva la facoltà di modificare le caratteristiche al fine di migliorare tecnicamente ed esteticamente il prodotto o

sospendere la produzione dei modelli in qualsiasi momento senza preavviso. Pesi e misure sono da considerarsi indicativi. Le misure di

installazione, riportate nei cataloghi, possono presentare differenze rispetto ai pezzi reali in considerazione delle peculiari caratteristiche di

fabbricazione degli articoli in ceramica

FORO COMPETENTE

Qualsiasi controversia fra Hidra Ceramica Srl e il Committente sarà di competenza soltanto del Foro di Viterbo (Italia), esclusa qualsiasi

altra deroga, anche nel caso di chiamata in giudizio per garanzia, connessione, contingenza di lite.

The present conditions of sale and delivery are considered as fully accepted by the Purchaser upon the order or the collection of the goods. Any

general conditions of sale of the Purchaser are rejected.

ACCETTAZIONE ORDINI

The orders are anyway subject to the prior consent of Hidra Ceramica Srl.

PRICES

Prices may be charged without notice and are agreed according to the price list in force on delivery. The prices of the present price list are

meant ex factory and don’t include V.A.T.

PAYMENT

Payment terms must be strictly respected starting from the invoice date. Payments should be made directly to Hidra Ceramica Srl at its hea-

dquarter. Any delay caused by the Purchaser or should any dispute arise between the parties as to the guarantees granted will not result in an

extension or change of the terms of payment agreed upon and any Purchaser’s action and exception will not be considered as prosecutable if

the Purchaser does not prove to be up-to-date with his payments. In case of delay in any payment the supplies under way may be interrupted or

cancelled. If no payments has been received within the terms set up in the invoice, Hidra Ceramica Srl will be authorized to issue a sight draft

for the total amount of its credit plus the relevant expenses. Any possible delay in the payment will result in the charge of interest at the market

current rate plus 2%. In case of failure to meet one of the payment dates the seller will be entitled to demand immediate payment of all other

invoices. Payment of all the invoices may also be demanded if the seller receives information about others circumstances which may indicate

that the purchaser’s financial situation is not sound (for example: issue of bouncing cheques, protested bills of exchange, attached proceeding).

DELIVERY TERMS, DELAYS OR OBSTACLES IN SUPPLY

When a delivery terms is stated, such term is given only for information purpose and is not binding since it is subject to any kind of contingency.

Delivery is considered as being completed when the goods are available at our factory in Civita Castellana (Italy). Work stoppage resulting from

act of God will exempt Hidra Ceramica Srl from the observance of the delivery term stated without giving the Purchaser the right to claim for

any kind of damages. The goods shall always be collected and shall not remain in stock for any reason. Any stock or storage expenses or other

costs will be charged to the Customer.

CARRIAGE

Except for particular condition, goods are delivered ex factory and travel at Purchaser’s risk even when they are delivered free port of destina-

tion. Partial supplies and early supply are permitted. The cost of transport is at Customer charge. Shipment are made on behalf of the buyer. In

case of damages, breakages and shortages, the buyer has to notify to our firm through the carrier at the moment of the delivery. The supplier

is the owner of the delivered goods up to the due payment. Terms of delivery are subject to variations and depending to the possibilities of the

moment. Our firm is not responsible for any delay or missing deliveries caused by any facts independent of our will and any claim for reimburse-

ment for any delay that may occur in delivery will not be accepted.

PACKAGING

The packaging is made in pallets and shrink. The cost of the packaging is charged to the Purchaser, unless otherwise agreed upon as specified

in the order confirmation. We charge of 3% for freights of packaging.

LIABILITY

If the material is defective due to manufacturing defects recognized by technical assessments, Hidra reserves the right to replace or to credit

the value in the time required by law. In no event shall the liability can extend to any direct or indirect which might arise also from the installation

of the defective material. It is burden of the buyer to check every item as soon as received, and so in particular to open the packaging and boxes

of containment; the period of revocation of law for defects apparent begins at the time of delivery thereof.

COMPLAINS

No complain of any kind will be accepted after eight days from the receipt of the goods. Possible complains should be made through a registe-

red letter within such term. In any case no objection will be accepted for already installed material.

TECHNICAL FEATURES AND COLORS

Hidra Ceramica Srl reserves the right to change the features of its products in order to improve them from the technical and aesthetic viewpoint

or to interrupt the production of certain models in any time without notice. Weight and measures are given only for information purposes.

Discrepancies may be found between the dimensions shown in the catalogues and the real pieces because of the manufacturing characteristi-

cs of the articles in ceramic.

COMPETENT COURT

Any dispute between Hidra Ceramica Srl and the Purchaser will be settled only by the Court of Viterbo (Italy), with no exception to such

rule, even in case of summons for guarantee, consolidation of actions or lawsuit contingency

242

243